The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1988 The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
Im Buch
Ergebnisse 1-5 von 78
Seite 12
... resulting con- solidated matrices may be included in agency acquisition regulations . ( f ) Dates . Since they are subject to revision from time to time , all provi- sions , clauses , and alternates are dated ; e.g. , ( DEC 1983 ) . To ...
... resulting con- solidated matrices may be included in agency acquisition regulations . ( f ) Dates . Since they are subject to revision from time to time , all provi- sions , clauses , and alternates are dated ; e.g. , ( DEC 1983 ) . To ...
Seite 18
... resulting from the award of this contract . ( b ) Agreement . The offeror agrees to pro- vide information relating to the above Rep- resentation as requested by the Contracting Officer and , when subparagraph ( a ) ( 1 ) or ( a ) ( 2 ) ...
... resulting from the award of this contract . ( b ) Agreement . The offeror agrees to pro- vide information relating to the above Rep- resentation as requested by the Contracting Officer and , when subparagraph ( a ) ( 1 ) or ( a ) ( 2 ) ...
Seite 27
... resulting from the Contractor's awaiting qualification approval by the Gov- ernment of a component or its manufactur- er shall not constitute excuseable delay when a previously qualified component could have been acquired in time to ...
... resulting from the Contractor's awaiting qualification approval by the Gov- ernment of a component or its manufactur- er shall not constitute excuseable delay when a previously qualified component could have been acquired in time to ...
Seite 31
... resulting contract unless author- ized in writing by the Contracting Officer . ( b ) All items to be furnished under the re- sultant contract must comply with the terms and specifications contained in the contract . ( End of provision ) ...
... resulting contract unless author- ized in writing by the Contracting Officer . ( b ) All items to be furnished under the re- sultant contract must comply with the terms and specifications contained in the contract . ( End of provision ) ...
Seite 35
... resulting damage will consist of liquidated damages until such reasonable time as may be re- quired for final completion of the work to- gether with any increased costs occasioned the Government in completing the work . ( c ) If the ...
... resulting damage will consist of liquidated damages until such reasonable time as may be re- quired for final completion of the work to- gether with any increased costs occasioned the Government in completing the work . ( c ) If the ...
Andere Ausgaben - Alle anzeigen
Häufige Begriffe und Wortgruppen
acceptance Administration agency agreement amended amount applicable authorized award basic clause bill of lading bond Certificate clause in solicitations completed computer software contract price Contracting Officer Contractor Contractor agrees Cost Accounting Standards cost or pricing Davis-Bacon Act delivered delivery Department End of clause End of provision equitable adjustment ernment facilities Federal Acquisition Regulation firm fixed-price following clause furnished GSA FAR 48 insert the following invoice Item jewel bearings ment modification Name & Address NAME AND ADDRESS NAME AND TITLE Name(s negotiated notice offer offeror paragraph performance performance bond period Prescribed by GSA PRIME CONTRACT progress payments purchase quantities quired receipt Reinsurance request settlement proposal shipment SIGNATURE small business concerns solicitations and contracts specified Standard Form subcon subcontract subject invention submit subparagraph Subpart supplies or services SURETY termination tion tracting Officer tractor Typed VECP ZIP Code
Beliebte Passagen
Seite 100 - All mechanics and laborers employed or working upon the site of the work, or under the United States Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the project, will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR Part 3...
Seite 190 - ... institution, including any Federal lending agency, and may thereafter be further assigned and reassigned to any such institution. Any such assignment or reassignment shall cover all amounts payable under this contract and not already paid, and shall not be made to more than one party...
Seite 134 - To the point of practical application" means to manufacture in the case of a composition or product, to practice in the case of a process, or...
Seite 226 - The Contractor shall do nothing to prejudice the Government's right to recover against third parties for any such loss, destruction or damage and, upon the request of the Contracting Officer, shall, at the Government's expense, furnish to the Government all reasonable assistance and cooperation (including the prosecution of suit and the execution of instruments of assignment in favor of the Government) in obtaining recovery.
Seite 197 - In this contract, or (2) unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inhering In work of the character provided for in this contract.
Seite 47 - ... it is determined by the Government that the late receipt was due solely to mishandling by the Government after receipt at the Government installation...
Seite 226 - Officer, provides for the relief of the subcontractor from such liability. In the absence of such approval, the subcontract shall contain appropriate provisions requiring the return of all Government property in as good condition as when received, except for reasonable wear and tear or for the utilization of the property in accordance with the provisions of the prime contract.
Seite 250 - ... (ii) if the Contractor fails to perform any of the other provisions of this contract, or so fails to make progress as to endanger performance of this contract in accordance with its terms, and in either of these two circumstances does not cure such failure within a period of 10 days (or such longer period as the Contracting Officer may authorize in writing) after receipt of notice from the Contracting Officer specifying such failure.
Seite 221 - Contractor, for use in connection with and under the terms of this contract, the property described in the Schedule or specifications, together with such related data and information as the Contractor may request and as may reasonably be required for the intended use of such property (hereinafter referred to as "Government-furnished Property...
Seite 127 - Contractor has knowledge. (b) In the event of any claim or suit against the Government on account of any alleged patent or copyright infringement arising out of the performance of this contract or out of the use of any supplies furnished or work or services performed hereunder, the Contractor shall furnish to the Government, when requested by the Contracting Officer, all evidence and information in possession of the Contractor pertaining to such suit or claim. Such evidence and information shall...